Free Construction Contract Template

CONSTRUCTION CONTRACT This Construction Contract (the "Agreement") is entered into as of [Effective Date] (the "Effective Date"), BETWEEN: [Contractor Name], with a principal place of business at [Contractor Address] (the "Contractor"); AND [Owner Name], with a principal place of business at [Owner Address] (the "Owner"). The Contractor and the Owner may be referred to individually as a "Party" and collectively as the "Parties." 1. SCOPE OF WORK AND PROJECT DESCRIPTION The Contractor will perform the following work at [Project Address]: [Scope of Work Description] (the "Work"), in accordance with applicable building codes and approved plans attached as Exhibit A (if any). 2. MATERIALS AND SPECIFICATIONS Materials and workmanship will meet: [Materials and Specifications]. Substitutions require Owner approval in writing. The Contractor warrants materials are new unless otherwise disclosed. 3. PROJECT TIMELINE AND MILESTONES Work begins on [Project Start Date] with substantial completion targeted by [Substantial Completion Date]. Milestones: [Project Milestones]. Delays caused by Owner changes, weather, or force majeure extend the schedule day-for-day. 4. PAYMENT SCHEDULE AND DRAW REQUESTS The contract price is [Contract Price]. Payments follow: [Payment Schedule]. The Contractor will submit draw requests with lien waivers from subcontractors and suppliers as required. The Owner will pay approved draws within [Draw Payment Days] days. 5. CHANGE ORDER PROCEDURES Changes to scope, price, or schedule require a signed change order before work begins: [Change Order Process]. Verbal approvals are not binding. Emergency work may proceed with subsequent written confirmation within [Emergency Change Order Days] days. 6. WARRANTIES AND GUARANTEES The Contractor warrants the Work for [Warranty Period] from substantial completion against defects in workmanship. Manufacturer warranties pass through to the Owner. Remedy is repair or replacement at Contractor's option. 7. INSURANCE AND LICENSING REQUIREMENTS The Contractor will maintain [Insurance Requirements], including general liability and workers' compensation as required by law. The Contractor represents it holds license [Contractor License Number] in good standing. 8. DISPUTE RESOLUTION AND LIEN WAIVERS Disputes will first be addressed through [Dispute Resolution Method]. The Contractor will provide conditional and final lien waivers with each payment. The Owner may withhold disputed amounts in escrow pending resolution as permitted by law. 9. GOVERNING LAW This Agreement is governed by the laws of [Governing Law / Jurisdiction], without regard to conflict-of-law principles. The courts located in [Governing Law / Jurisdiction] will have exclusive jurisdiction over disputes arising out of or relating to this Agreement, unless the Parties agree in writing to mediation before litigation. 10. GENERAL (a) Entire Agreement. This Agreement constitutes the entire agreement between the Parties concerning its subject matter and supersedes prior or contemporaneous agreements on that subject. (b) Amendments. Modifications must be in writing and signed by both Parties. (c) Severability. If any provision is held unenforceable, the remaining provisions remain in effect. (d) Assignment. Neither Party may assign this Agreement without the other Party's prior written consent, except to a successor in connection with a merger, acquisition, or sale of substantially all assets. (e) Counterparts and Electronic Signatures. This Agreement may be executed in counterparts, including electronic signatures, each of which will be deemed an original. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the Effective Date. CONTRACTOR Name: [Contractor Name] Signature: _______________________________ Name of Signatory: _______________________ Title: ___________________________________ Date: ____________________________________ OWNER Name: [Owner Name] Signature: _______________________________ Name of Signatory: _______________________ Title: ___________________________________ Date: ____________________________________